{
  "url": "https://openlegislation.uk/net-zero-teesside-order-2024/schedule-12/paragraph-357",
  "json_url": "https://openlegislation.uk/net-zero-teesside-order-2024/schedule-12/paragraph-357.json",
  "legislation": "uksi/2024/174",
  "legislation_title": "The Net Zero Teesside Order 2024",
  "legislation_url": "https://openlegislation.uk/net-zero-teesside-order-2024",
  "path": "schedule/12/paragraph/357",
  "kind": "paragraph",
  "number": "357",
  "heading": "Removal or diversion of apparatus",
  "text": "(1) If, in the exercise of the powers conferred by this Order, the undertaker acquires any interest in land in which the apparatus is placed, that apparatus must not be removed under this Part or otherwise, and any right of Northern Gas Networks to maintain that apparatus in that land must not be extinguished until alternative apparatus has been constructed and is in operation to the reasonable satisfaction of Northern Gas Networks in accordance with sub-paragraphs (2) to (5).\n(2) If, for the purpose of executing any works in, on or under any land purchased, held, appropriated or used under this Order, the undertaker requires the removal or diversion of any apparatus placed in that land, it must give to Northern Gas Networks written notice of that requirement, together with a plan of the works and the removal or diversion works proposed, the proposed position of the alternative apparatus, and the proposed timeline for the works. Northern Gas Networks must reasonably approve these details. The undertaker must afford to Northern Gas Networks, to their reasonable satisfaction, the necessary facilities and rights for—\n(a) the construction of alternative apparatus in other land of the undertaker; and\n(b) the maintenance of that apparatus,\nand after the alternative apparatus to be provided or constructed has been agreed or settled by arbitration in accordance with article 47 (arbitration) and after the grant to Northern Gas Networks of any such facilities and rights, Northern Gas Networks must complete the works and bring the alternative apparatus into operation and subsequently remove any apparatus required to be removed by the undertaker and must use its reasonable endeavours to meet the undertaker’s proposed timeline, and in any event must do so without undue delay, in accordance with the details provided by the undertaker under this sub-paragraph or as otherwise reasonably agreed by the undertaker.\n(3) If, in consequence of the works carried out by the undertaker, Northern Gas Networks reasonably needs to remove or divert any of its apparatus, it must without undue delay give the undertaker written notice of that requirement, together with a plan of the work proposed, the proposed position of the alternative apparatus and the proposed timeline for the works. The undertaker must reasonably approve these details and must afford to Northern Gas Networks, to their reasonable satisfaction, the necessary facilities and rights for—\n(a) the construction of alternative apparatus in other land of the undertaker; and\n(b) the maintenance of that apparatus,\nand after the alternative apparatus to be provided or constructed has been agreed or settled by arbitration in accordance with article 47 (arbitration) and after the grant to Northern Gas Networks of any such facilities and rights, Northern Gas Networks must complete the works and bring the alternative apparatus into operation and subsequently remove any apparatus required to be removed by the undertaker without undue delay and in accordance with the approved details and timeline.\n(4) If alternative apparatus or any part of such apparatus is to be constructed elsewhere than in other land of the undertaker, or the undertaker is unable to afford such facilities and rights as are mentioned in sub-paragraphs (2) and (3) in the land in which the alternative apparatus or part of such apparatus is to be constructed, Northern Gas Networks must, on receipt of a written notice to that effect from the undertaker, as soon as reasonably possible take such steps as are reasonable in the circumstances (at the Undertaker’s expense) to obtain the necessary facilities and rights in the land in which the alternative apparatus is to be constructed.\n(5) Paragraphs 359 (expenses) and 360 (indemnity) of this Part of this Schedule apply to removal or diversions works under this paragraph 356, subject to Northern Gas Networks providing to the undertaker in advance and in writing (to the extent practicable) a reasonable cost estimate for works that it proposes to carry out.",
  "extent": "E+W+S",
  "status": null,
  "version": "current",
  "annotations": [
    {
      "type": "I",
      "label": "I1",
      "text": "Sch. 12 para. 357 in force at 11.3.2024, see art. 1"
    }
  ],
  "outstanding_effects": [],
  "provenance": {
    "source": "legislation.gov.uk",
    "source_url": "https://www.legislation.gov.uk/uksi/2024/174/schedule/12/paragraph/357",
    "retrieved_at": "2026-10-28T21:34:40.750770+00:00"
  },
  "licence": "Open Government Licence v3.0",
  "licence_url": "https://www.nationalarchives.gov.uk/doc/open-government-licence/version/3/",
  "attribution": "Contains public sector information licensed under the Open Government Licence v3.0. Source: legislation.gov.uk, The National Archives."
}